Please read these terms carefully before using our website or services
Last Updated: May 2026
Welcome to the official website of BIGBUILDUP DEVELOPERS PVT LTD ("Company", "we", "us", or "our"), accessible at https://thebigbuildup.com (the "Website"). These Terms and Conditions ("Terms") constitute a legally binding agreement between you ("User", "you", or "your") and the Company. By accessing or using this Website, engaging our services, or making any payment through our platform, you acknowledge that you have read, understood, and agree to be bound by these Terms in their entirety. If you do not agree to any part of these Terms, you must immediately discontinue use of this Website and our services. Your continued use of the Website following any modifications to these Terms shall constitute acceptance of such changes.
BIGBUILDUP DEVELOPERS PVT LTD is a company incorporated under the Companies Act, 2013, and registered under the laws of India. The Company is engaged in the business of infrastructure engineering and related services.
Registered Office Address:
BIGBUILDUP DEVELOPERS PVT LTD
Ground Floor 01 & 02, 21 A, Montessori Lane,
Boring Road, Patna, Bihar - 800001, India
Email: admin@thebigbuildup.com
Website: https://thebigbuildup.com
BIGBUILDUP DEVELOPERS PVT LTD is a professional infrastructure engineering firm providing a comprehensive range of services including, but not limited to:
(a) Highway construction and road development;
(b) Bridge engineering and structural design;
(c) Industrial infrastructure development;
(d) Urban development and civil construction;
(e) Tender consulting, project estimation, and bid management;
(f) Surveying, geotechnical analysis, and site investigation;
(g) Project management and engineering consultancy;
(h) Any other infrastructure-related services as offered by the Company from time to time.
The scope, specifications, deliverables, timelines, and commercial terms for each engagement shall be defined in a separate service agreement, work order, or contract executed between the Company and the client.
All service engagements with BIGBUILDUP DEVELOPERS PVT LTD are subject to the execution of a formal agreement or acceptance of a quotation/proposal issued by the Company. Digital retainer payments, advance payments, and milestone-based payments lock technical personnel, survey crews, engineering teams, and analysis capabilities for designated project coordinates and timelines. Once a service engagement is authorized and payment is processed, assigned resources and project schedules cannot be adjusted retroactively unless mutually agreed upon in writing by both parties.
Clients are responsible for providing accurate project information, site access, necessary permits, and any other requirements as communicated by the Company for the timely execution of services. Delays caused by the client's failure to fulfil these obligations shall not constitute a breach on the part of the Company.
All payments for services rendered by BIGBUILDUP DEVELOPERS PVT LTD shall be made in Indian Rupees (INR) unless otherwise agreed in writing. The Company uses CCAvenue, a PCI-DSS compliant payment gateway, to process online payments securely. All online payment transactions are processed in compliance with the guidelines and regulations issued by the Reserve Bank of India (RBI), including but not limited to the RBI's guidelines on digital payments, data localization, and consumer protection.
Payment Methods: We accept payments via credit cards, debit cards, net banking, UPI, and other digital payment modes as supported by CCAvenue.
Payment Security: All payment information is encrypted and processed through CCAvenue's secure payment infrastructure. The Company does not store your credit/debit card details or banking credentials on its servers. All sensitive payment data is handled directly by CCAvenue in compliance with PCI-DSS standards.
Transaction Confirmation: Upon successful payment, you will receive a transaction confirmation via email. This confirmation serves as your payment receipt. Please retain this for your records.
Payment Failures: In the event of a payment failure or incomplete transaction, the debited amount (if any) will be refunded to your original payment method within 5-7 business days, subject to banking procedures and timelines. If the amount is not refunded within this period, please contact us at admin@thebigbuildup.com with your transaction details.
Currency & Taxes: All prices and fees quoted on the Website or in proposals are exclusive of applicable taxes (including GST) unless expressly stated otherwise. Applicable taxes shall be charged as per prevailing government regulations at the time of invoicing.
Refund Policy: Refunds, if applicable, shall be processed in accordance with the Company's Refund Policy available at Refund Policy. All refund requests are subject to the terms and conditions stated therein.
All content, materials, designs, logos, trademarks, trade names, parametric design models, spatial estimates, engineering drawings, tender validation files, reports, methodologies, software, and any other intellectual property displayed on this Website or produced during the course of service delivery are and shall remain the exclusive proprietary assets of BIGBUILDUP DEVELOPERS PVT LTD, protected under the Copyright Act, 1957, the Trade Marks Act, 1999, and other applicable intellectual property laws of India.
No intellectual property or deliverable produced by the Company shall be transferred to the client until all commercial milestones, payments, and contractual obligations have been fully cleared and satisfied. Unauthorized use, reproduction, distribution, modification, display, or transmission of any Company intellectual property is strictly prohibited and may result in legal action.
As a user of this Website and/or a client of our services, you agree to:
(a) Provide accurate, current, and complete information as required for service engagement, payment processing, and communication;
(b) Maintain the confidentiality of any account credentials, project-related information, or sensitive data shared with you;
(c) Not use the Website or our services for any unlawful, fraudulent, or unauthorized purpose;
(d) Not attempt to gain unauthorized access to any part of the Website, its servers, or any systems connected to the Website;
(e) Not transmit any viruses, malware, or other harmful code through the Website;
(f) Comply with all applicable local, state, national, and international laws and regulations;
(g) Not impersonate any person or entity or misrepresent your affiliation with any person or entity;
(h) Not interfere with or disrupt the operation of the Website or the servers and networks used to make the Website available.
The content on this Website, including but not limited to text, images, graphics, photographs, videos, project showcases, and other materials, is provided for general informational purposes only. While we strive to keep the information accurate and up to date, the Company makes no representations or warranties of any kind, express or implied, about the completeness, accuracy, reliability, suitability, or availability of the information, products, services, or related graphics contained on the Website for any purpose.
Unauthorized reproduction, duplication, copying, selling, reselling, or exploitation of any content, images, designs, or materials from this Website, in whole or in part, without the express written permission of BIGBUILDUP DEVELOPERS PVT LTD is strictly prohibited. Any reliance you place on the information provided on this Website is at your own risk.
To the maximum extent permitted by applicable law, BIGBUILDUP DEVELOPERS PVT LTD, its directors, officers, employees, agents, partners, and affiliates shall not be liable for any direct, indirect, incidental, special, consequential, punitive, or exemplary damages, including but not limited to damages for loss of profits, goodwill, data, business opportunities, or other intangible losses, arising out of or in connection with:
(a) Your use of or inability to use the Website or our services;
(b) Any unauthorized access to or alteration of your data or transmissions;
(c) Any interruption, suspension, or termination of the Website or services;
(d) Any errors, inaccuracies, or omissions in the content on the Website;
(e) Any third-party content, products, or services accessed through the Website;
(f) Any matter relating to the Website or our services, regardless of the theory of liability (contract, tort, negligence, strict liability, or otherwise).
In no event shall the Company's total aggregate liability to you for all claims arising out of or related to the Website or services exceed the total amount paid by you to the Company in the twelve (12) months preceding the event giving rise to such liability.
You agree to indemnify, defend, and hold harmless BIGBUILDUP DEVELOPERS PVT LTD, its directors, officers, employees, agents, contractors, and affiliates from and against any and all claims, liabilities, damages, losses, costs, and expenses (including reasonable legal fees and disbursements) arising out of or in connection with:
(a) Your use of the Website or our services;
(b) Your breach or alleged breach of any of these Terms;
(c) Your violation of any applicable law, rule, regulation, or the rights of any third party;
(d) Any content, information, or material you submit, post, or transmit through the Website;
(e) Any negligent, reckless, or wilful misconduct on your part.
This indemnification obligation shall survive the termination of these Terms and your use of the Website.
In the event of any dispute, controversy, or claim arising out of or relating to these Terms, the Website, or the services provided by the Company ("Dispute"), the parties shall first attempt to resolve the Dispute through good-faith negotiation and amicable settlement within thirty (30) days of one party notifying the other in writing of the Dispute.
If the Dispute cannot be resolved through negotiation, it shall be referred to and finally resolved by arbitration in accordance with the Arbitration and Conciliation Act, 1996 (as amended). The arbitration shall be conducted by a sole arbitrator mutually appointed by both parties. The seat and venue of arbitration shall be Patna, Bihar, India. The language of the arbitration proceedings shall be English. The arbitral award shall be final and binding on both parties.
Nothing in this clause shall prevent either party from seeking interim or injunctive relief from a court of competent jurisdiction.
These Terms and Conditions shall be governed by, construed, and interpreted in accordance with the laws of the Republic of India, without regard to its conflict of law principles. Any legal action, suit, or proceeding arising out of or relating to these Terms or the use of the Website that is not subject to arbitration as provided above shall be instituted exclusively in the competent courts located in Patna, Bihar, India, and you hereby consent to the personal and exclusive jurisdiction of such courts.
BIGBUILDUP DEVELOPERS PVT LTD reserves the right to modify, amend, update, or replace these Terms and Conditions at any time, at its sole discretion, without prior notice. Any changes will be effective immediately upon posting the revised Terms on this Website with an updated "Last Updated" date. It is your responsibility to review these Terms periodically for any changes. Your continued use of the Website or our services after any modifications to these Terms constitutes your acceptance of the revised Terms. If you do not agree with any modified Terms, you must discontinue your use of the Website and services immediately.
If any provision of these Terms and Conditions is found to be invalid, illegal, or unenforceable by any court or tribunal of competent jurisdiction, such invalidity, illegality, or unenforceability shall not affect the remaining provisions of these Terms, which shall continue in full force and effect. The invalid or unenforceable provision shall be deemed modified to the minimum extent necessary to make it valid and enforceable while preserving its original intent, or if such modification is not possible, it shall be deemed severed from these Terms.
Entire Agreement: These Terms, together with our Privacy Policy, Refund Policy, and Shipping Policy, constitute the entire agreement between you and the Company with respect to your use of the Website and supersede all prior or contemporaneous communications, proposals, and agreements, whether electronic, oral, or written, between you and the Company.
Waiver: No failure or delay by the Company in exercising any right, power, or remedy under these Terms shall operate as a waiver thereof, nor shall any single or partial exercise of any right, power, or remedy preclude any other or further exercise thereof or the exercise of any other right, power, or remedy.
Assignment: You may not assign, transfer, or sublicense any of your rights or obligations under these Terms without the prior written consent of the Company. The Company may assign its rights and obligations under these Terms without restriction.
Force Majeure: The Company shall not be liable for any failure or delay in performance resulting from causes beyond its reasonable control, including but not limited to acts of God, natural disasters, pandemics, war, terrorism, government actions, strikes, or disruptions in telecommunications or internet services.
For any questions, concerns, or communications regarding these Terms and Conditions, please contact us at:
BIGBUILDUP DEVELOPERS PVT LTD
Ground Floor 01 & 02, 21 A, Montessori Lane,
Boring Road, Patna, Bihar - 800001, India
Email: admin@thebigbuildup.com
Website: https://thebigbuildup.com
Our team is available to clarify any terms or conditions related to our services.
